FIX, §1A diff (2015 → 2016)

ITEM 1A. Risk Factors Our business is subject to a variety of risks. You should carefully consider the risks described below, together with all the information included in this report. Our business, financial condition and results of operations could be adversely affected by the occurrence of any of these events, which could cause actual results to differ materially from expected and historical results, and the trading price of our common stock could decline. Many of the markets we do work in are currently experiencing an economic downturn or might in the future experience an economic downturn that may materially and adversely affect our business because our business is dependent on levels of construction activity. The demand for our services is dependent upon the existence of construction projects and service requirements within the markets in which we operate. Any period of economic recession affecting a market or industry in which we transact business is likely to adversely impact our business. Many of the projects we work on have long lifecycles from conception to completion, and the bulk of our performance generally occurs late in a construction project’s lifecycle. We experience the results of economic trends well after an economic cycle begins, and therefore will continue to experience the results of an economic recession well after conditions in the general economy have improved. The industries and markets we operate in have always been and will continue to be vulnerable to macroeconomic downturns because they are cyclical in nature. When there is a reduction in demand, it often leads to greater price competition as well as decreased revenue and profit. The lasting effects of a recession can also increase economic instability with our vendors, subcontractors, developers, and general contractors, which can cause us greater liability exposure and can result in us not being paid on some projects, as well as decreasing our revenue and profit. Further, to the extent some of our vendors, subcontractors, developers, or general contractors seek bankruptcy protection, the bankruptcy will likely force us to incur additional costs in attorneys’ fees, as well as other professional consultants, and will result in decreased revenue and profit. Additionally, a reduction in federal, state, or local government spending in our industries and markets could result in decreased revenue and profit for us. Because we bear the risk of cost overruns in most of our contracts, we may experience reduced profits or, in some cases, losses under these contracts if costs increase above our estimates. Our contract prices are established largely upon estimates and assumptions of our projected costs, including assumptions about: future economic conditions; prices, including commodities prices; availability of labor, including the costs of providing labor, equipment, and materials; and other factors outside our control. If our estimates or assumptions prove to be inaccurate, if circumstances change in a way that renders our assumptions and estimates inaccurate or we fail to successfully execute the work, cost overruns may occur and we could experience reduced profits or a loss for affected projects. For instance, unanticipated technical problems may arise, we could have difficulty obtaining permits or approvals, local laws, labor costs or labor conditions could change, bad weather could delay construction, raw materials prices could increase, our suppliers or subcontractors may fail to perform as expected or site conditions may be different than we expected. We are also exposed to increases in energy prices, particularly as they relate to gasoline prices. Additionally, in certain circumstances, we guarantee project completion or the achievement of certain acceptance and performance testing levels by a scheduled date. Failure to meet schedule or performance requirements typically results in additional costs to us, and in some cases we may also create liability for consequential and liquidated damages. Performance problems for existing and future projects could cause our actual results of operations to differ materially from those we anticipate and could damage our reputation within our industry and our customer base. Our backlog is subject to unexpected adjustments and cancellations, which means that amounts included in our backlog may not result in actual revenue or translate into profits. The revenue projected from our backlog may not be realized, or, if realized, may not result in profits. Projects may remain in our backlog for an extended period of time, or project cancellations or scope adjustments may occur with respect to contracts reflected in our backlog. Intense competition in our industry could reduce our market share and our profit. The markets we serve are highly fragmented and competitive. Our industry is characterized by many small companies whose activities are geographically concentrated. We compete on the basis of our technical expertise and experience, financial and operational resources, nationwide presence, industry reputation and dependability. While we believe our customers consider a number of these factors in awarding available contracts, a large portion of our work is awarded through a bid process. Consequently, price is often the principal factor in determining which contractor is selected, especially on smaller, less complex projects. Smaller competitors are sometimes able to win bids for these projects based on price alone due to their lower cost and financial return requirements. We expect competition to intensify in our industry, presenting us with significant challenges in our ability to maintain strong growth rates and acceptable profit margins. We also expect increased competition from in-house service providers, because some of our customers have employees who perform service work similar to the services we provide. Vertical consolidation is also expected to intensify competition in our industry. If we are unable to meet these competitive challenges, we will lose market share to our competitors and experience an overall reduction in our profits. In addition, our profitability would be impaired if we have to reduce our prices to remain competitive. Our recent and future acquisitions may not be successful. We expect to continue pursuing selective acquisitions of businesses. We cannot assure that we will be able to locate acquisitions or that we will be able to consummate transactions on terms and conditions acceptable to us, or that acquired businesses will be profitable. Acquisitions may expose us to additional business risks different than those we have traditionally experienced. We also may encounter difficulties integrating acquired businesses and successfully managing the growth we expect to experience from these acquisitions. We may choose to finance future acquisitions with debt, equity, cash or a combination of the three. Future acquisitions could dilute earnings or disrupt the payment of a stockholder dividend. To the extent we succeed in making acquisitions, a number of risks will result, including: · the assumption of material liabilities (including for environmental-related costs); · failure of due diligence to uncover situations that could result in legal exposure or to quantify the true liability exposure from known risks; · the diversion of management’s attention from the management of daily operations to the integration of operations; · difficulties in the assimilation and retention of employees, in the assimilation of different cultures and practices, in the assimilation of broad and geographically dispersed personnel and operations, and the retention of employees generally; · the risk of additional financial and accounting challenges and complexities in areas such as tax planning, treasury management, financial reporting and internal controls; and · we may not be able to realize the cost savings or other financial benefits we anticipated prior to the acquisition. The failure to successfully integrate acquisitions could have an adverse effect on our business, financial condition and results of operations. Information technology system failures, network disruptions or cyber security breaches could adversely affect our business. We use sophisticated information technology systems, networks, and infrastructure in conducting some of our day-to-day operations and providing services to certain customers. Information technology system failures, including suppliers’ or vendors’ system failures, could disrupt our operations by causing transaction errors, processing inefficiencies, the loss of customers, other business disruptions or the loss of employee personal information. In addition, these systems, networks, and infrastructure may be vulnerable to deliberate cyber-attacks that interfere with their functionality or the confidentiality of our information or our customers’ data. These events could impact our customers, employees and reputation and lead to financial losses from remediation actions, loss of business or potential liability or an increase in expense, all of which may have a material adverse effect on our business. Third parties contribute significantly to our completion of many projects. We hire third-party subcontractors to perform work and depend on third-party suppliers to provide equipment and materials necessary to complete our projects. If we are unable to retain qualified subcontractors or suppliers, or if our subcontractors or suppliers do not perform as anticipated for any reason, our execution and profitability could be harmed. Earnings for future periods may be impacted by impairment charges for goodwill and intangible assets. We carry a significant amount of goodwill and identifiable intangible assets on our consolidated balance sheets. Goodwill is the excess of purchase price over the fair value of the net assets of acquired businesses. We assess goodwill for impairment each year, and more frequently if circumstances suggest an impairment may have occurred. We have determined in the past and may again determine in the future that a significant impairment has occurred in the value of our unamortized intangible assets or fixed assets, which could require us to write off a portion of our assets and could adversely affect our financial condition or our reported results of operations. Actual and potential claims, lawsuits and proceedings could ultimately reduce our profitability and liquidity and weaken our financial condition. We are likely to continue to be named as a defendant in legal proceedings claiming damages from us in connection with the operation of our business. These actions and proceedings may involve claims for, among other things, compensation for alleged personal injury, workers’ compensation, employment discrimination, breach of contract or property damage. In addition, we may be subject to class action lawsuits involving allegations of violations of the Fair Labor Standards Act and state wage and hour laws. Due to the inherent uncertainties of litigation, we cannot accurately predict the ultimate outcome of any such actions or proceedings. We also are, and are likely to continue to be, from time to time a plaintiff in legal proceedings against customers, in which we seek to recover payment of contractual amounts we are owed as well as claims for increased costs we incur. When appropriate, we establish provisions against possible exposures, and we adjust these provisions from time to time according to ongoing exposure. If our assumptions and estimates related to these exposures prove to be inadequate or inaccurate, we could experience a reduction in our profitability and liquidity and a weakening of our financial condition. In addition, claims, lawsuits and proceedings may harm our reputation or divert management resources away from operating our business. We typically warrant the services we provide, guaranteeing the work performed against defects in workmanship and the material we supply. Historically, warranty claims have not been material as our customers evaluate much of the work we perform for defects shortly after work is completed. However, if warranty claims occur, we could be required to repair or replace warrantied items at our cost. In addition, our customers may elect to repair or replace the warrantied item by using the services of another provider and require us to pay for the cost of the repair or replacement. Costs incurred as a result of warranty claims could adversely affect our operating results and financial condition. Our use of the percentage-of-completion method of accounting could result in a reduction or reversal of previously recorded revenue or profits. A material portion of our revenue is recognized using the percentage-of-completion method of accounting, which results in our recognizing contract revenue and earnings ratably over the contract term in the proportion that our actual costs bear to our estimated contract costs. The earnings or losses recognized on individual contracts are based on estimates of contract revenue, costs and profitability. We review our estimates of contract revenue, costs and profitability on an ongoing basis. Prior to contract completion, we may adjust our estimates on one or more occasions as a result of change orders to the original contract, collection disputes with the customer on amounts invoiced or claims against the customer for increased costs incurred by us due to customer-induced delays and other factors. Contract losses are recognized in the fiscal period when the loss is determined. Contract profit estimates are also adjusted in the fiscal period in which it is determined that an adjustment is required. As a result of the requirements of the percentage-of-completion method of accounting, the possibility exists, for example, that we could have estimated and reported a profit on a contract over several periods and later determined, usually near contract completion, that all or a portion of such previously estimated and reported profits were overstated. If this occurs, the full aggregate amount of the overstatement will be reported for the period in which such determination is made, thereby eliminating all or a portion of any profits from other contracts that would have otherwise been reported in such period or even resulting in a loss being reported for such period. On a historical basis, we believe that we have made reasonably reliable estimates of the progress towards completion on our long-term contracts. However, given the uncertainties associated with these types of contracts, it is possible for actual costs to vary from estimates previously made, which may result in reductions or reversals of previously recorded revenue and profits. A significant portion of our business depends on our ability to provide surety bonds. Any difficulties in the financial and surety markets may adversely affect our bonding capacity and availability. In the past we have expanded, and it is possible we will continue to expand, the number and percentage of total contract dollars that require an underlying bond. Historically surety market conditions have experienced times of difficulty as a result of significant losses incurred by many surety companies and the results of macroeconomic trends outside of our control. Consequently, during times when less overall bonding capacity is available in the market, surety terms have become more expensive and more restrictive. As such, we cannot guarantee our ability to maintain a sufficient level of bonding capacity in the future, which could preclude our ability to bid for certain contracts or successfully contract with some customers. Additionally, even if we continue to be able to access bonding capacity to sufficiently bond future work, we may be required to post collateral to secure bonds, which would decrease the liquidity we would have available for other purposes. Our surety providers are under no commitment to guarantee our access to new bonds in the future; thus, our ability to access or increase bonding capacity is at the sole discretion of our surety providers. If our surety companies were to limit or eliminate our access to bonds, our alternatives would include seeking bonding capacity from other surety companies, increasing business with clients that do not require bonds and posting other forms of collateral for project performance, such as letters of credit or cash. We may be unable to secure these alternatives in a timely manner, on acceptable terms, or at all. As such, if we were to experience an interruption or reduction in the availability of bonding capacity, it is likely we would be unable to compete for or work on certain projects. We are a decentralized company and place significant decision making powers with our subsidiaries’ management, which presents certain risks. We believe that our practice of placing significant decision making powers with local management is important to our successful growth and allows us to be responsive to opportunities and to our customers’ needs. However, this practice presents certain risks, including the risk that we may be slower or less effective in our attempts to identify or react to problems affecting an important business than we would under a more centralized structure or that we would be slower to identify a misalignment between a subsidiary’s and the Company’s overall business strategy. Further, if a subsidiary location fails to follow the Company’s compliance policies, we could be made party to a contract, arrangement or situation that requires the assumption of large liabilities or has less advantageous terms than is typically found in the market. Our insurance policies against many potential liabilities require high deductibles, and our risk management policies and procedures may leave us exposed to unidentified or unanticipated risks. Additionally, difficulties in the insurance markets may adversely affect our ability to obtain necessary insurance. Although we maintain insurance policies with respect to our related exposures, these policies are subject to high deductibles; as such, we are, in effect, self-insured for substantially all of our typical claims. We hire an actuary to determine any liabilities for unpaid claims and associated expenses for the three major lines of coverage (workers’ compensation, general liability and auto liability). The determination of these claims and expenses and the appropriateness of the estimated liability are reviewed and updated quarterly. However, insurance liabilities are difficult to assess and estimate due to the many relevant factors, the effects of which are often unknown, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents that have occurred but are not reported and the effectiveness of our safety program. Our accruals are based on known facts, historical trends (both internal trends and industry averages) and our reasonable estimate of our future expenses. We believe our accruals are adequate. However, our risk management strategies and techniques may not be fully effective in mitigating our risk exposure in all market environments or against all types of risk. If any of the variety of instruments, processes or strategies we use to manage our exposure to various types of risk are not effective, we may incur losses that are not covered by our insurance policies or that exceed our accruals or coverage limits. Additionally, we typically are contractually required to provide proof of insurance on projects we work on. Historically insurance market conditions become more difficult for insurance consumers during periods when insurance companies suffer significant investment losses as well as casualty losses. Consequently, it is possible that insurance markets will become more expensive and restrictive. Also, our prior casualty loss history might adversely affect our ability to procure insurance within commercially reasonable ranges. As such, we may not be able to maintain commercially reasonable levels of insurance coverage in the future, which could preclude our ability to work on many projects. Our insurance providers are under no commitment to renew our existing insurance policies in the future; therefore, our ability to obtain necessary levels or kinds of insurance coverage is subject to market forces outside our control. If we were unable to obtain necessary levels of insurance, it is likely we would be unable to compete for or work on most projects. Failure to remain in compliance with covenants under our credit agreement, service our indebtedness, or fund our other liquidity needs could adversely impact our business. Our credit agreement and related restrictive and financial covenants are more fully described in Note 9 of “Notes to the Consolidated Financial Statements.” Our failure to comply with any of these covenants, or to pay principal, interest or other amounts when due thereunder, would constitute an event of default under the credit agreement. Default under our credit agreement could result in (1) us no longer being entitled to borrow under the agreement; (2) termination of the agreement; (3) acceleration of the maturity of outstanding indebtedness under the agreement; and/or (4) foreclosure on any collateral securing the obligations under the agreement. If we are unable to service our debt obligations or fund our other liquidity needs, we could be forced to curtail our operations, reorganize our capital structure (including through bankruptcy proceedings) or liquidate some or all of our assets in a manner that could cause holders of our securities to experience a partial or total loss of their investment in us. If we experience delays and/or defaults in customer payments, we could be unable to recover all expenditures. Because of the nature of our contracts, at times we commit resources to projects prior to receiving payments from the customer in amounts sufficient to cover expenditures on projects as they are incurred. Delays in customer payments may require us to make a working capital investment. If a customer defaults in making their payments on a project to which we have devoted resources, it could have a material negative effect on our results of operations. If we are unable to attract and retain qualified managers and employees, we will be unable to operate efficiently, which could reduce our profitability. Our business is labor intensive, and many of our operations experience a high rate of employment turnover. At times of low unemployment rates in the United States, it will be more difficult for us to find qualified personnel at low cost in some geographic areas where we operate. Additionally, our business is managed by a small number of key executive and operational officers. We may be unable to hire and retain the sufficient skilled labor force necessary to operate efficiently and to support our growth strategy. Our labor expenses may increase as a result of a shortage in the supply of skilled personnel. Labor shortages, increased labor costs or the loss of key personnel could reduce our profitability and negatively impact our business. Further, our relationship with some customers could suffer if we are unable to retain the employees with whom those customers primarily work and have established relationships. Our inability to properly utilize our workforce could have a negative impact on our profitability. The extent to which we utilize our workforce affects our profitability. Underutilizing our workforce could result in lower gross margins and, consequently, a decrease in short-term profitability. On the other hand, overutilization of our workforce could negatively impact safety, employee satisfactions and project execution, leading to a potential decline in future project awards. The utilization of our workforce is impacted by numerous factors, including: · our estimate of headcount requirements and our ability to manage attrition; · efficiency in scheduling projects and our ability to minimize downtime between project assignments; and · productivity. Misconduct by our employees, subcontractors or partners or our overall failure to comply with laws or regulations could harm our reputation, damage our relationships with customers, reduce our revenue and profits, and subject us to criminal and civil enforcement actions. Misconduct, fraud, non-compliance with applicable laws and regulations, or other improper activities by one or more of our employees, subcontractors or partners could have a significant negative impact on our business and reputation. Examples of such misconduct include employee or subcontractor theft, the failure to comply with safety standards, laws and regulations, customer requirements, environmental laws and any other applicable laws or regulations. While we take precautions to prevent and detect these activities, such precautions may not be effective and are subject to inherent limitations, including human error and fraud. Our failure to comply with applicable laws or regulations or acts of misconduct could subject us to fines and penalties, harm our reputation, damage our relationships with customers, reduce our revenue and profits and subject us to criminal and civil enforcement actions. Failure or circumvention of our disclosure controls and procedures or internal controls over financial reporting could seriously harm our financial condition, results of operations, and our business. We plan to continue to maintain and strengthen internal controls and procedures to enhance the effectiveness of our disclosure controls and internal controls over financial reporting. Any system of controls, however well designed and operated, is based in part on certain assumptions and can provide only reasonable, and not absolute, assurances that the objectives of the system are met. Any failure of our disclosure controls and procedures or internal controls over financial reporting could harm our financial condition and results of operations. We have subsidiary operations through the United States and are exposed to multiple state and local regulations, as well as federal laws and requirements applicable to government contractors. Changes in law, regulations or requirements, or a material failure of any of our subsidiaries or us to comply with any of them, could increase our costs and have other negative impacts on our business. Our 91 locations are located in 27 states, which exposes us to a variety of different state and local laws and regulations, particularly those pertaining to contractor licensing requirements. These laws and regulations govern many aspects of our business, and there are often different standards and requirements in different locations. In addition, our subsidiaries that perform work for federal government entities are subject to additional federal laws and regulatory and contractual requirements. Changes in any of these laws, or any of our subsidiaries’ material failure to comply with them, can adversely impact our operations by, among other things, increasing costs, distracting management’s time and attention from other items, and harming our reputation. As government contractors, our subsidiaries are subject to a number of rules and regulations, and their contracts with government entities are subject to audit. Violations of the applicable rules and regulations could result in a subsidiary being barred from future government contracts. Government contractors must comply with many regulations and other requirements that relate to the award, administration and performance of government contracts. A violation of these laws and regulations could result in imposition of fines and penalties, the termination of a government contract or debarment from bidding on government contracts in the future. Further, despite our decentralized nature, a violation at one of our locations could impact other locations’ ability to bid on and perform government contracts; additionally, because of our decentralized nature, we face risks in maintaining compliance with all local, state and federal government contracting requirements. Prohibition against bidding on future government contracts could have an adverse effect on our financial condition and results of operations. Past and future environmental, safety and health regulations could impose significant additional costs on us that reduce our profits. HVAC systems are subject to various environmental statutes and regulations, including the Clean Air Act and those regulating the production, servicing and disposal of certain ozone-depleting refrigerants used in HVAC systems. There can be no assurance that the regulatory environment in which we operate will not change significantly in the future. Various local, state and federal laws and regulations impose licensing standards on technicians who install and service HVAC systems. And additional laws, regulations and standards apply to contractors who perform work that is being funded by public money, particularly federal public funding. Our failure to comply with these laws and regulations could subject us to substantial fines, the loss of our licenses or potentially debarment from future publicly funded work. It is impossible to predict the full nature and effect of judicial, legislative or regulatory developments relating to health and safety regulations and environmental protection regulations applicable to our operations. Unsatisfactory safety performance may subject us to penalties, affect customer relationships, result in higher operating costs, negatively impact employee morale and result in higher employee turnover. Our projects are conducted at a variety of sites including construction sites and industrial facilities. Each location is subject to numerous safety risks, including electrocutions, fires, explosions, mechanical failures, weather-related incidents, transportation accidents and damage to equipment. These hazards can cause personal injury and loss of life, severe damage to or destruction of property and equipment and other consequential damages and could lead to suspension of operations, large damage claims and, in extreme cases, criminal liability. While we have taken what we believe are appropriate precautions to minimize safety risks, we have experienced serious accidents, including fatalities, in the past and may experience additional accidents in the future. Serious accidents may subject us to penalties, civil litigation or criminal prosecution. Claims for damages to persons, including claims for bodily injury or loss of life, could result in significant costs and liabilities, which could adversely affect our financial condition and results of operations. Poor safety performance could also jeopardize our relationships with our customers and harm our reputation. If we do not effectively manage the size and cost of our operations, our existing infrastructure may become either strained or over-burdensome, and we may be unable to increase revenue growth. The growth that we have experienced in the past, and that we may experience in the future, may provide challenges to our organization, requiring us to expand our personnel and our operations. Future growth may strain our infrastructure, operations and other managerial and operating resources. We have also experienced in the past severe constriction in the markets in which we operate and, as a result, in our operating requirements. Failing to maintain the appropriate cost structure for a particular economic cycle may result in our incurring costs that affect our profitability. If our business resources become strained or over-burdensome, our earnings may be adversely affected and we may be unable to increase revenue growth. Further, we may undertake contractual commitments that exceed our labor resources, which could also adversely affect our earnings and our ability to increase revenue growth. We are susceptible to adverse weather conditions, which may harm our business and financial results. Our business may be adversely affected by severe weather in areas where we have significant operations. Repercussions of severe weather conditions may include: · curtailment of services; · suspension of operations; · inability to meet performance schedules in accordance with contracts and potential liability for liquidated damages; · injuries or fatalities; · weather related damage to our facilities; · disruption of information systems; · inability to receive machinery, equipment and materials at jobsites; and · loss of productivity. Future climate change could adversely affect us. Climate change may create physical and financial risk. Physical risks from climate change could, among other things, include an increase in extreme weather events (such as floods or hurricanes), rising sea levels and limitations on water availability and quality. Such extreme weather conditions may limit the availability of resources, increasing the costs of our projects, or may cause projects to be delayed or cancelled. Legislation, nationwide protocols, regulation or other restrictions related to climate change could negatively impact our operations or our customers’ operations. Such legislation or restrictions could increase the costs of projects for our customers or, in some cases, prevent a project from going forward, which could in turn have an adverse effect on our financial condition and results of operations. Force majeure events, including natural disasters and terrorists’ actions, could negatively impact our business, which may affect our financial condition, results of operations or cash flows. Force majeure or extraordinary events beyond the control of the contracting parties, such as natural and man-made disasters, as well as terrorist actions, could negatively impact us. We typically negotiate contract language where we are allowed certain relief from force majeure events in private client contracts and review and attempt to mitigate force majeure events in both public and private client contracts. We remain obligated to perform our services after most extraordinary events subject to relief that may be available pursuant to a force majeure clause. If we are not able to react quickly to force majeure events, our operations may be affected significantly, which would have a negative impact on our financial position, results of operations, cash flows and liquidity. Deliberate, malicious acts, including terrorism and sabotage, could damage our facilities, disrupt our operations or injure employees, contractors, customers or the public and result in liability to us. Intentional acts of destruction could damage or destroy our facilities, reducing our operational production capacity and requiring us to repair or replace our facilities at substantial cost. Additionally, employees, contractors and the public could suffer substantial physical injury from acts of terrorism for which we could be liable. Governmental authorities may also impose security or other requirements that could make our operations more difficult or costly. The consequences of any such actions could adversely affect our financial condition and results of operations. Our common stock, which is listed on the New York Stock Exchange, has from time to time experienced significant price and volume fluctuations. These fluctuations are likely to continue in the future, and our stockholders may suffer losses. The market price of our common stock may change significantly in response to various factors and events beyond our control. A variety of events may cause the market price of our common stock to fluctuate significantly, including the following: (i) the risk factors described in this Report on Form 10-K; (ii) a shortfall in operating revenue or net income from that expected by securities analysts and investors; (iii) quarterly fluctuations in our operating results; (iv) changes in securities analysts’ estimates of our financial performance or that of our competitors or companies in our industry generally; (v) general conditions in our customers’ industries; (vi) general conditions in the securities markets; (vii) our announcements of significant contracts, milestones, acquisitions; (viii) our relationship with other companies; (ix) our investors’ view of the sectors and markets in which we operate; and (x) additions or departures of key personnel. Some companies that have volatile market prices for their securities have been subject to security class action suits filed against them. If a suit were to be filed against us, regardless of the outcome, it could result in substantial costs and a diversion of our management’s attention and resources. This could have a material adverse effect on our business, results of operations and financial condition. We are required to assess and report on our internal controls each year. Findings of inadequate internal controls could reduce investor confidence in the reliability of our financial information. As directed by the Sarbanes-Oxley Act, the SEC adopted rules generally requiring public companies, including us, to include in their annual reports on Form 10-K a report of management that contains an assessment by management of the effectiveness of our internal control over financial reporting. In addition, the independent registered public accounting firm auditing our financial statements must report on the effectiveness of our internal control over financial reporting. A company’s internal control over financial reporting is a process designed by, or under the supervision of, the company’s principal executive and principal financial officers, or persons performing similar functions, and effected by the company’s board of directors, management, and other personnel to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles and that receipts and expenditures of the company are being made only in accordance with authorizations of management and records of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the financial statements. We may discover in the future that we have deficiencies in the design and operation of our internal controls. If any of the deficiencies in our internal control, either by itself or in combination with other deficiencies, becomes a “material weakness”, such that there is a reasonable possibility that a material misstatement of the annual or interim financial statements will not be prevented or detected on a timely basis, we may be unable to conclude that we have effective internal control over financial reporting. In such event, investors could lose confidence in the reliability of our financial statements, which may significantly harm our business and cause our stock price to decline. In addition, the failure to maintain effective internal controls could also result in unauthorized transactions. Future sales of our common stock may depress our stock price. Sales of a substantial number of shares of our common stock in the public market or otherwise, either by us, a member of management or a major stockholder, or the perception that these sales could occur, could depress the market price of our common stock and impair our ability to raise capital through the sale of additional equity securities. Increases and uncertainty in our health insurance costs could adversely impact our results of operations and cash flows. The costs of employee health insurance have been increasing in recent years due to rising health care costs, legislative changes, and general economic conditions. Additionally, we may incur additional costs as a result of the Patient Protection and Affordable Care Act (the “Affordable Care Act”) that was signed into law in March 2010. It is possible that following the inauguration of President Trump on January 20, 2017, legislation will be introduced and passed by the Republican-controlled Congress repealing the Affordable Care Act in whole or in part and signed into law by President Trump, consistent with statements made by him during his presidential campaign indicating his intention to do so within a short time following his inauguration. Because of the continued uncertainty about the implementation of the Affordable Care Act, including the potential for further legal challenges or repeal of that legislation, we cannot quantify or predict with any certainty the likely impact of the Affordable Care Act or its repeal on our financial position or results of operations. Rising inflation and/or interest rates could have an adverse effect on our business, financial condition and results of operations. Economic factors, including inflation and fluctuations in interest rates, could have a negative impact on our business. If our costs were to become subject to significant inflationary pressures or interest rate increases, we may not be able to fully offset such higher costs through price increases. Our inability or failure to do so could harm our financial position and results of operations. Our effective tax rate may increase. We conduct business across the United States and file income taxes in various tax jurisdictions. Our effective tax rates could be affected by many factors, some of which are outside of our control, including changes in tax laws and regulations in the various tax jurisdictions in which we file income taxes, issues relating to tax audits or examinations and any related interest or penalties, and uncertainty in obtaining deductions or credits claimed in various jurisdictions. Our results of operations is reported based on our determination of the amount of taxes we owe in various tax jurisdictions. Significant judgment is required in determining our provision for income taxes and our determination of tax liability is always subject to review or examination by tax authorities in applicable tax jurisdictions. An adverse outcome of such a review of examination could adversely affect our operating results and financial condition. Further, the results of tax examinations and audits could have a negative impact on our financial results and cash flows where the results differ from the liabilities recorded in our financial statements. Our charter contains certain anti-takeover provisions that may inhibit or delay a change in control. Our certificate of incorporation authorizes our board of directors to issue, without stockholder approval, one or more series of preferred stock having such preferences, powers and relative, participating, optional and other rights (including preferences over the common stock respecting dividends and distributions and voting rights) as the board of directors may determine. The issuance of this “blank-check” preferred stock could render more difficult or discourage an attempt to obtain control by means of a tender offer, merger, proxy contest or otherwise. Additionally, certain provisions of the Delaware General Corporation Law may also discourage takeover attempts that have not been approved by the Board of Directors. ITEM 1B.